Md. Code Regs. 21.07.01.06

Current through Register Vol. 51, No. 21, October 18, 2024

Section 21.07.01.06 - Disputes

Mandatory provision for all contracts. One of the following clauses is preferred:

A. Alternate Disputes Clause (short form). "This contract shall be subject to the provisions of State Finance and Procurement Article, Title 15, Subtitle 2, Annotated Code of Maryland, and COMAR 21.10 (Administrative and Civil Remedies). Pending resolution of a claim, the Contractor shall proceed diligently with the performance of the contract in accordance with the procurement officer's decision."

B. Alternate Disputes Clause (long form).

(1) This contract is subject to the provisions of State Finance and Procurement Article, Title 15, Subtitle 2, Annotated Code of Maryland and COMAR 21.10 (Administrative and Civil Remedies).

(2) Except as otherwise may be provided by law, all disputes arising under or as a result of a breach of this contract that are not disposed of by mutual agreement shall be resolved in accordance with this clause.

(3) As used herein, "claim" means a written demand or assertion by one of the parties seeking, as a legal right, the payment of money, adjustment or interpretation of contract terms, or other relief, arising under or relating to this contract. A voucher, invoice, or request for payment that is not in dispute when submitted is not a claim under this clause. However, if the submission subsequently is not acted upon in a reasonable time, or is disputed as to liability or amount, it may be converted to a claim for the purpose of this clause.

(4) A claim shall be made in writing and submitted to the procurement officer for decision in consultation with the Office of the Attorney General.

(5) When a claim cannot be resolved by mutual agreement, the contractor shall submit a written request for final decision to the procurement officer. The written request shall set forth all the facts surrounding the controversy.

(6) The contractor, at the discretion of the procurement officer, may be afforded an opportunity to be heard and to offer evidence in support of the contractor's claim.

(7) The procurement officer shall render a written decision on all claims within 180 days of receipt of the contractor's written claim, unless the procurement officer determines that a longer period is necessary to resolve the claim. If a decision is not issued within 180 days, the procurement officer shall notify the contractor of the time within which a decision shall be rendered and the reasons for such time extension. The decision shall be furnished to the contractor, by certified mail, return receipt requested, or by any other method that provides evidence of receipt. The procurement officer's decision shall be deemed the final action of the State.

(8) The procurement officer's decision shall be final and conclusive unless the contractor mails or otherwise files a written appeal with the Maryland State Board of Contract Appeals within 30 days of receipt of the decision.

(9) Pending resolution of a claim, the contractor shall proceed diligently with the performance of the contract in accordance with the procurement officer's decision."

Md. Code Regs. 21.07.01.06

Regulation .06 amended effective 49:9 Md. R.531, eff. 5/2/2022