Summary
In Moskowitz v Tory Burch LLC, 161 AD3d 525, 526, 77 NYS3d 364 [1st Dept 2018]), the Court considered the Administrative Code and property damage, and in doing so, still engaged in a proximate causation analysis: "Plaintiff established prima facie that TBLLC cause[d]' soil or foundation work to be made, pursuant to the license agreement, and that the work proximately caused damage to his building" (id.). Defendants' engineer claimed that testing the soil will be helpful in determining the cause and extent of the damages to the property, which is at issue in this case.
Summary of this case from 452 E. 118th St. LLC. v. 329 Pleasant Ave. Mazal Holdings LLCOpinion
6559 Index 159599/15
05-15-2018
Herbert MOSKOWITZ, doing business as Manhattan Realty Company, Plaintiff–Appellant, v. TORY BURCH LLC, et al., Defendants–Respondents, New York City Department of Buildings, Defendant.
Peluso & Touger, LLP, New York (Robert R. Moore, Jr. of counsel), for appellant. Wasserman Grubin & Rogers, L.L.P., New York (Richard Wasserman of counsel), for Tory Burch LLC, respondent. Fabiani Cohen & Hall, LLP, New York (Kevin B. Pollak of counsel), for Skanska USA Building Inc., respondent. Kennedys CMK LLP, New York (Joseph P. McNulty of counsel), for Thornton Tomasetti, Inc., respondent. Lewis Brisbois Bisgaard & Smith LLP, New York (Steven R. Montgomery of counsel), for Langan Engineering Environmental Surveying & Landscaping Architecture PPC, respondent.
Peluso & Touger, LLP, New York (Robert R. Moore, Jr. of counsel), for appellant.
Wasserman Grubin & Rogers, L.L.P., New York (Richard Wasserman of counsel), for Tory Burch LLC, respondent.
Fabiani Cohen & Hall, LLP, New York (Kevin B. Pollak of counsel), for Skanska USA Building Inc., respondent.
Kennedys CMK LLP, New York (Joseph P. McNulty of counsel), for Thornton Tomasetti, Inc., respondent.
Lewis Brisbois Bisgaard & Smith LLP, New York (Steven R. Montgomery of counsel), for Langan Engineering Environmental Surveying & Landscaping Architecture PPC, respondent.
Richter, J.P., Andrias, Webber, Gesmer, Moulton, JJ.
Order, Supreme Court, New York County (Robert R. Reed, J.), entered July 11, 2017, which denied plaintiff's motion for partial summary judgment on the claims for breach of contract, strict liability, and attorneys' and experts' fees, unanimously modified, on the law, to grant the motion as against defendant Tory Burch LLC (TBLLC) with respect to the strict liability claim and the part of the breach of contract claim premised on the obligation contained in section 9(a) of the license agreement between plaintiff, TBLLC and defendant Skanska USA Building Inc., and otherwise affirmed, without costs.
Plaintiff alleges that damage was caused to a building he owns, at 153 Mercer Street in Manhattan, as a result of work performed at an adjacent property, at 151 Mercer Street, leased to defendant Tory Burch LLC (TBLLC) for the planned construction of a four-story retail building. In connection with the construction project, TBLLC retained defendant Skanska USA Building Inc. as the construction manager, defendant Langan Engineering, Environmental, Surveying and Landscape Architecture, PPC as the geotechnical engineer, and defendant Thornton Tomasetti, Inc. (TT) as the structural engineer.
Plaintiff established prima facie that TBLLC "cause[d]" soil or foundation work to be made, pursuant to the license agreement, and that the work proximately caused damage to his building (see N.Y. City Building Code [Administration Code of City of N.Y. tit 28, ch 7] § BC 28–3309.4; Coronet Props. Co. v. L/M Second Ave., 166 A.D.2d 242, 243, 560 N.Y.S.2d 444 [1st Dept. 1990] [deciding motion for summary judgment on claim under Administrative Code former § 27–1031, now § 28–3309.4] ). Plaintiff's evidence included an affidavit by Robert Moskowitz, an employee, who asserted on the basis of personal knowledge that the building was damaged after pile drilling was performed on TBLLC's behalf on the side of the 151 Mercer lot adjacent to 153 Mercer. TT's subsequent investigation on TBLLC's behalf concluded that the work on the project had caused damage to plaintiff's building. In opposition to plaintiff's motion, TBLLC failed to raise an issue of fact; its objections to plaintiff's evidence merely raise issues as to the nature and the extent of the damage to plaintiff's building attributable to the construction work.
In a related proceeding brought by TBLLC, this Court reversed an order that had granted TBLLC a judicial license to enter plaintiff's property to take steps to protect it (see
TT's reports should have been considered as party admissions (see Buckley v. J.A. Jones/GMO, 38 A.D.3d 461, 463, 832 N.Y.S.2d 560 [1st Dept. 2007], citing Penn v. Kirsh, 40 A.D.2d 814, 338 N.Y.S.2d 161 [1st Dept. 1972] ) and as admissions by an agent, since TT prepared the reports as TBLLC's agent to assess damage to plaintiff's building and recommend how to proceed (see Rosasco v. Cella, 124 A.D.3d 447, 1 N.Y.S.3d 71 [1st Dept. 2015], citing Georges v. American Export Lines, 77 A.D.2d 26, 33, 432 N.Y.S.2d 165 [1st Dept. 1980] ). However, the reports are inadmissible against Skanska and Langan. Thus, plaintiff failed to meet his prima facie burden as to them.
Plaintiff established through evidence of the nature and timing of the damage that the damage was sustained after the license agreement was entered into, on April 2, 2015 (see New Life Holding Corp. v. Turner Constr. Co., 2014 N.Y. Slip Op. 32590[U], 2014 WL 5023524 [Sup Ct, N.Y. County 2014] ). This evidence was consistent with the pile drilling schedule and TT's report that "[t]he majority of the movement at [plaintiff's building] appears to have taken place between June 10, 2015 and June 29, 2015" (compare O'Hara v. New School, 118 A.D.3d 480, 987 N.Y.S.2d 386 [1st Dept. 2014] [no prima facie case under BC § 3309.4 where no evidence proffered that the requisite license under the statute was granted] ).
Contrary to TBLLC's contention, the statute imposes strict liability (see Yenem Corp. v. 281 Broadway Holdings, 18 N.Y.3d 481, 491, 941 N.Y.S.2d 20, 964 N.E.2d 391 [2012] ; American Sec. Ins. Co. v Church of God of St. Albans, 131 A.D.3d 903, 905, 16 N.Y.S.3d 247 [2d Dept. 2015] ). As to TT and Langan, plaintiff failed to establish that either of them was a "person who cause[d]" soil or foundation work to be made (BC § 3309.4; see 87 Chambers, LLC v. 77 Reade, LLC, 122 A.D.3d 540, 998 N.Y.S.2d 15 [1st Dept. 2014] ).
Plaintiff is correct that the terms of section 4(g) of the license agreement impose a reporting obligation on TBLLC and Skanska. However, while he established that the obligation was breached, he failed to establish any damages flowing from the breach (see Viacom Outdoor, Inc. v. Wixon Jewelers, Inc., 82 A.D.3d 604, 919 N.Y.S.2d 151 [1st Dept. 2011] ; Lexington 360 Assoc. v First Union Natl. Bank of N. Carolina, 234 A.D.2d 187, 189–190, 651 N.Y.S.2d 490 [1st Dept. 1996] ).
Plaintiff is also correct that section 4(h) of the license agreement imposes a consulting obligation in connection with "any work potentially affecting the elevator shaft." This provision is unambiguous on its face (see Chimart Assoc. v. Paul, 66 N.Y.2d 570, 498 N.Y.S.2d 344, 489 N.E.2d 231 [1986] ). Had the parties desired to limit its application to masonry voids, they could have done so. However, plaintiff failed to establish damages resulting from the alleged breach of this provision, merely stating conclusorily that, had he been notified, pursuant to the provision, the damages would have been avoided.
Plaintiff failed to establish a breach of the provision requiring TBLLC and Skanska to indemnify him for attorneys' fees and professional fees. He did not identify the nature of the legal or expert fees sought. Nor did he allege, much less establish, that he made a demand for payment and the demand was refused.
Plaintiff established prima facie his entitlement to recovery under article 9 of the license agreement, which required TBLLC to pay him "$100.00 ... for each calendar day that site protection or monitoring devices remain ... after April 30, 2016 ..., unless delay is caused solely by Moskowitz's unreasonable action or unreasonable delay" (emphasis added). In opposition, TBLLC failed to submit admissible evidence showing that the delay in removing the equipment was attributable "solely" to plaintiff.
Matter of Tory Burch LLC v. Moskowitz, 146 A.D.3d 528, 43 N.Y.S.3d 901 [1st Dept. 2017] ).