Section 7085.6 - Automatic suspension for failure to comply with arbitration award; reinstatement(a)(1) The failure of a licensee to comply with an arbitration award rendered under this article shall result in the automatic suspension of a license by operation of law.(2) The registrar shall notify the licensee by certified mail of the failure to comply with the arbitrator's award, and that the license shall be automatically suspended 30 calendar days from the date of that notice.(3) The licensee may appeal the suspension for noncompliance within 15 calendar days after service of the notice by written notice to the registrar.(4) Reinstatement may be made at any time following the suspension by complying with the arbitrator's award and the final order of the registrar. If no reinstatement of the license is made within 90 days of the date of the automatic suspension, the license and any other contractor's license issued to the licensee shall be automatically revoked by operation of law for a period to be determined by the registrar pursuant to Section 7102.(5) The registrar may delay, for good cause, the revocation of a contractor's license for failure to comply with the arbitration award. The delay in the revocation of the license shall not exceed one year. When seeking a delay of the revocation of his or her license, a licensee shall apply to the registrar in writing prior to the date of the revocation of the licensee's license by operation of law and state the reasons that establish good cause for the delay. The registrar's power to grant a delay of the revocation shall expire upon the effective date of the revocation of the licensee's license by operation of law.(b) The licensee shall be automatically prohibited from serving as an officer, director, associate, partner, manager, or qualifying individual of another licensee, for the period determined by the registrar and the employment, election, or association of that person by another licensee shall constitute grounds for disciplinary action. A qualifier disassociated pursuant to this section shall be replaced within 90 days from the date of disassociation. Upon failure to replace the qualifier within 90 days of the disassociation, the license of the other licensee shall be automatically suspended or the qualifier's classification removed at the end of the 90 days.Ca. Bus. and Prof'l. Code § 7085.6
Amended by Stats 2010 ch 698 (SB 392),s 24, eff. 1/1/2011.Amended by Stats 2003 ch 363 (AB 1382), s 3, eff. 1/1/2004.